Exhibit,Appendix: Kevin Mcgonigal v. Nyy Steak Manhattan, Llc, Plaza Construction Corp., Baring Industries, Inc.

• 
• 
• 
• 
• 
• 
• 
• 

						
                                
Preview
                                (FILED: NEW YORK COUNTY CLERK 26/95/2014 INDEX NO. 158327/2013

NYSCEF DOC. NO. 8 . \ RECEIVED NYSCEF:

PLAZA

CONSTRUCTION

NYY STEAK MANHATTAN, LLC (“NYY STEAK”)
7 West 515" STREET
New York, New York 10020

TRADE SUBCONTRACT

“KITCHEN EQUIPMENT WORK”

Barinc INoustRies, INC.
3249 S.W, 42° Street
Fr. LAUDERDALE, FLORIDA 33311

06/05/2014

SUBMITTED To: BARING INDUSTRIES, INC.
MANNY ALVAREZ

SUBMITTED BY: PLAZA CONSTRUCTION CorRP,
MICHAEL J. GABBAY

Date: May 13,2013ARTICLE 1.
ARTICLE 2.

ARTICLE 3.
ARTICLE 4.
ARTICLE 5,
ARTICLE 6.
ARTICLE 7.
ARTICLE 8.
ARTICLE 9,
ARTICLE 10.
ARTICLE 11,

INDEX

Contract Price: Scope of the Work.

Certain Obligations of the Subcontractor to the
Owner, Construction Manager and Architect ....scssssesssessesesscssesseecenernernssnneend

Terms of Payment.

Scheduling....scceccsccsserecneecsecvesssessnsessssesssaesssaneeseesqeaneqnesseanerenseescsusaseesessenonugeannegs 6

Progress .

insurance

Default and Termination.

ARTICLE 12. No Waiver Except in Writing...cecsessestessecses ecsescreseeeeevacssnaseesneaessneneeeseaseensensnents 1
ARTICLE 13. Assignments...

ARTICLE 14, Merger ...cssseesccsssstsssscesessesssessecsecseesseeanssseesnesuscueeeeseseneceneescesssanseavesrasnsenanenseessys 12
ARTICLE 15. Amendments

ARTICLE 16. Captions

ARTICLE 17. Notices ...cccscscssecescsesesesessseaneeaveesversusessscsessosaeersasensesersntensenereedsassvesessersaserensecess cit 12
ARTICLE 18. Miscellaneous

ARTICLE 19, No Third Party Baneficicty....sececsscsssnesecteceseeeeerisenesecasierennsssereaneeaeeneneaeenenenncniitiny 12
LIST OF EXHIBITS

NYY Steak, Rev, 5.20.13 initial Below: Plaza & SipegpiestoeTRADE SUBCONTRACT

THIS TRADE SUBCONTRACT is entered into as of the 13" day of May, 2013, by and between
BARING INDUSTRIES, INC., a corporation, having its office at 3249 S.W, 42% STREET, FT. LAUDERDALE
FLORIDA 33312. ("Subcontractor"], and PLAZA CONSTRUCTION CORP., a NEW YORK corporation, having its
office AT 1065 AVENUE OF THE AMERICAS, New York, New York 10018 ("Construction Manager’).

WHEREAS, Construction Manoger has entered into an agreement (the “Agreement") with NYY.
STEAK MANHATTAN, LLC (“NYY STEAK”), ("Owner") to perform contracting services in connection with the
construction of NYY STEAK, at a sife located at Z West 51% Srreet, New York, New York 10020
("Project"); and

WHEREAS, the Owner has also retained the services of SOSH, to provide licensed architectural and
consulting engineering services in connection with the Project (collectively, the "Architect"); and

WHEREAS, Construction Manager, subject to Owner's approval, has awarded this Subcontract
"Subcontract or "Contract") as hereinafter defined, to the Subcontractor and the Subcontractor has agreed to
enter info this Subcontract, and to perform the Work required or described herein or reasonably inferable from
the Contract Documents in order to achieve the intended resulis;

NOW, THEREFORE, in consideration of the foregoing and of the mutual covenants contained
herein, the Subcontractor and the Construction Manager agree as follows:

ARTICLE 1: Subcontract Price: Scope of the Work

11 Subject to oll of the terms and conditions herein contained, Subcontractor shall receive the
total Contract Price of _NINE HUNDRED NINETY THOUSAND. dollars ($990,000.00) {the "Contract Price”)
{which price is firm, not subject to escalation, and includes all applicable federal, state and municipal taxes
now or hereafter enacted} for the full and faithful performance and completion of all of ils obligations uncer
this Coniract, ‘including but not limited to the performance and completion of all requirements of the Contract
Documents, as hereinafier defined, all labor necessary to complete such construction, all materials and
equipment (whether for femporary or permanent use) incorporated or to be incorporated in such construction,
all tools, equipment, supplies, superintendence, insurance, bonds, taxes and all other services and facilities
necessary fo complete and perform the following (the "Work"):

Furnish ond Install Kitchen Equipment Work- See Attached Scope of Work — “Exhibit C.”

REV.5.21.13 2 Initial Below:___Plaza Construction Subcontractor

Mn1.2 The Work shall include; without limitation, the preparation, delivery and installation or
erection, as the case may be, of materials and machinery, scaffolding, tools, equipment and ail transportation
cartage, loading and hoisting, pattems, models, surveys, field measurements or other measurements, shop
drawings, temporary light and heat (unless otherwise provided by Construction Manager}, protection of work
and labor from winter conditions, safety requirements, contributions to union funds and benefits, payment of
royalties, and all temporary relocations and construction. Without limiting the foregoing or the provisions of
the General Conditions, any Work shown on drawings and not mentioned in specifications, or described in
specifications and not shown on drawings, or included in the attached Scope of Work and not included in
either the drawings or the specifications, shall be included in the Work. The Subcontractor shall faithfully and
diligently undertake ond complete the Work fo comply in every respect with this Subegniract and the other
Contract Documents,

13 For purposes of this Contracl, the "Contract Documents" shall consist of:

a} This Trade Subcontract.

lb) General Conditions annexed hereto as Exhibit A.

{c}__ Listing of Plans and Specifications annexed hereto as Exhibit B.

ld} Subcontractor's Scope of Work annexed hereto as Exhibit C.

le} Progress Schedule annexed hereto as Exhibit D.

ff] insurance Requirements annexed hereto as Exhibit E.

ig) Subcontractor's Payment/Performance Bonds annexed hereto as Exhibit F (if
requested by Construction Manager].

fh} Wage Rates / Unit Prices annexed hereto as Exhibit G.

i) Alternate Prices annexed hereto as Exhibit H.

i) Project Site Safety Program annexed hereto as Exhibit |.

kk} Shop Drawings and other submittals as, and fo the extent, approved by the Architect.

ARTICLE 2: Certain Obligations of the Subcontractor

21 The Subcontractor affirms that it has visited the site and has become familior with all
conditions at the site. Without limiting any other provision hereof, the Subcontractor shall perform the Work
and its obligations under this Contract in accordance with and subject to each of the provisions of the Contract
Documents to the fullest extent that each such provision is applicable to the Work. In the event of any
inconsistency between or among the terms and conditions of the Contract Documents, the more restrictive
provision or the greater quantity, as applied to the Subcontractor, shall govern.

2.2 The Subcontractor shall undertake and complete the Work under the direction and
supervision of and to the entire satisfaction of, the Construction Manager, the Architect, and the Owner. The
Construction Manager shall provide the Subcontractor with one set of drawings and specifications for the
Work. Additional copies of drawings and specifications will be provided at the Subcontractor's expense, At
the Subcontractor's expense {unless otherwise specifically provided], the Architect shall provide such additional
drawings, details and explanations as may be necessary to detail and illustrate the Work, and the
Subcontractor shall conform to and abide by any such drawings, details and explanations.

2.3 The Subcontractor, if it subcontracts any part of the Work, shall enter into agreements
substantially similar to this Contract with each such subcontractor and shall require that each such
subcontractor read and expressly agree in writing: {i] to be bound by all provisions of the Contract Documents

REV.5.21.13 3 Initial Betow: se Subcontractorapplicable to its Work, including but not limited to the payment provisions stated herein; {ii} to provide
indemnity to the Owner, Construction Manager and Architect as provided in the General Conditions; and {iii)
to name the Owner, Construction Manager and Architect as Additional Insured under Subcontractors general
liability policy and provide Certificates of Insurance to that effect and otherwise reasonably satisfactory to
Construction Manager.

24 Subcontractor, and its sub-subcontractors of any tier, shall attend coordination meetings as
and when scheduled by Construction Manager and shall patticipate {or prepare if required elsewhere herein}
and cooperate in the preparation of composite drawings detailing the interrelationship of the various
components of Subcontractor's work with the work to be performed by others.

ARTICLE 3: Terms of Payment

3.4 If the Subcontractor is making satisfactory progress with the Work {in the Construction
Manager's reasonable opinion), is not in default under this Contract or under any other Contract Document, is
in compliance with all the documentation requirements by this Contract and as stated below, the Construction
Manager shall pay the Subcontractor the proportionate amount of the funds received from the Owner for
approved Work and materials within seven (7) days after receipt of funds from the Owner. Construction
Manager will, subject io the General Conditions and Section 3.2 below, make monthly payments to the
Subcontractor. equal fo ninety (90%) percent of the value of Work properly performed during such month.
Subcontractor agrees to look solely to such funds received by Construction Manager from Owner or to the
Owner directly for payments due hereunder. Subcontractor acknowledges and agrees that in the event
payment is not made to Construction Manager for any reason, including but not limited to default by the
Owner, or delays in processing Owner's financing for the Project, Subcontractor shall not be entitled to
payment from Construction Manager until such time as Construction Manager shail in good faith have
exhausted all legal remedies to enforce such payment from Owner without, in any fashion limiting, impairing
Subcontractor's lien rights under applicable law. Retention shall be paid to the Subcontractor in accordance
with the General Conditions as and when released by Owner, less any amounts applied fo cure any default
by Subcontractor under this Contract.

3.2 in order to receive any payment for the Work, the Subcontractor must comply with the
terms and conditions of the Contract Documents and must furnish with each Application for Payment the
following documentation or such other information as may be required by Consiruction Manager or Owner,

a. partial waivers of liens from Subcontractor, its Sub-Subcontractors and materialmen;

b. an affidavit warranting that all Work for which payments have been previously
made by Construction Manager are free and clear of liens, claims, security
interests or encumbrances;

¢. evidence of equipment purchases, rentals and other detailed support as the
Construction Manager may reasonably require;

d. evidence of stored material (if any) including but not limited to:
i, a bill of sale and other documentation satisfactory in form and
substance to Construction Manager, Owner {and Owner's Lender).

i}. a written list identifying each location where materials are stored off
the Project site and the value of materials at each location,

iii, evidence that Subcontractor has procured insurance satisfactory fo the
Construction Manager and Owner for materials stored off the Project site
in an amount not less than the full replacement value thereof; and

e. evidence to support the reasonableness of the Schedule of Valves.

REV.S.21,13 4 Initial Below: Plaza Cc tion Subgontractor

aon,3,3 a. Notwithstanding anything fo the contrary in this Contract or the existence of any
performance ér labor or material payment bond, the Construction Manager is hereby empowered to withhold
om the Subcontractor an amount, equal in the opinion of the Construction Manager te the amounts necessary
to complete the entire Work, (or any part thereof], necessary to compensate Construction Manager for any
unexcused delay on the part of Subcontractor, or necessary to pay and fully discharge any claims or liens
arising out of the Work performed under this Contract that may arise and be unpaid, for which, if established,
the Construction Manager or the Owner may become liable. If any such obligations, claims or liens exceed
the amount of the Contract Price then unpaid, or arise after the full Contract Price has been paid or otherwise
satisfied in accordance with and sublect to the terms and conditions hereof, the Subcontractor, immediately
upon demand, shall pay to the Construction Manager or Owner, as the case may be, all monies that the
Construction Manager or Owner may have paid or become obligated to pay to discharge such obligations,
tens or claims with respect fo the Project. In addition, Construction Manager may withhold payment due to
the: .

i, _ unsatisfactory or disputed job progress;
ii defective work not remedied;
iii, failure to carry out the Work in accordance with the Contract Documents;

iv. failure of the Subcontractor to make timely payments for labor including collectively
bargained fringe benefit contributions, payroll taxes and insurance;

v. damage to Construction Manager, Owner or another subcontractor or material
supplier;

vi. reasonable evidence that the Work cannot be completed for the unpaid balance of
the Contract Price;

vii. reasonable evidence that the Work will not be completed within the Contract Time and
that the unpaid balance would not be adequate to cover the cost of damages for the
anticipated delay;

viii, third party claims or liens filed or reasonable evidence indicating probable filing of
claims or liens, unless security acceptable to the Owner is provided by the Construction
Manager;

ix, Subcontractor's failure fo furnish any information required by the Contract Documents;

x. failure to provide evidence that Subcontractor’s insurance is in effect in accordance
with this Contract;

xi. failure of Subcontractor fo make timely payments fo its Sub-Subcontractors and material
suppliers;

xii, erroneous estimates by Subcontractor of the value of the Work performed; or

xiii, material safety violations by the Subcontractor or violations of other legal requirements.

b. Subcontractor shall be responsible for making payment to its Sub-Subcontractors and materialmen
wilhin seven (7) days of receipt of payment from Construction Manager, and shall (upon request} provide
evidence to Construction Manager of such payments.

34 ‘The Subcontractor expressly agrees that the Contract Price includes (a) all Work provided
for in the drawings and specifications, together with all work reasonably inferable therefrom, and (b} all
increases in cost, foreseen or unforeseen, including, without limiting the generality of the foregoing, taxes,
REV.5.21.13 5 Initial Below; __Plaza Constrwotion __Subeoatractor

Qumlabor and materials, the cost of all of which is fo be borne solely by the Subcontractor, All loss or damage
arising from any of the Work through unforeseen or unusual obstructions, difficulties or delays which may be
encountered in the prosecution of same or through the action of the elements shall be borne by the
Subcontractor, It is mutually agreed between the parties hereto that no payment made under this Contract
shall be conclusive evidence of the performance of this Contract by Subcontractor, either wholly or in part, nor
shall it be construed to be an acceptance of defective Work or materials, or an approval of any of the items in
any requisitions made or invoice rendered. All invoices or requests for payments must be presented in writing
in such form as may be required by Construction Manager. Provided payments are made to Subcontractor as
provided for hereunder, Subcontractor shall pay all costs necessary for the completion of the Work in
accordance with the Contract Dacumenis.

3.5 Subcontractor shall use the sums advanced to it pursuant to this Article 3 solely for the
purpose of performance of the Work and the construction, furnishing, and equipping of the Project in
accordance with the Contract Documents. Any and all funds paid to Subcontractor hereunder are hereby
declared to constitute trust funds in the hands of Subcontractor, to be applied before application to any other
purpose fo the payment of: (a} claims of subcontractors, sub-laborers, materialmen or other entities performing
work and employed by Subcontractor, {b} to claims for utilities furnished and taxes imposed, and to the
payment of premiums on surety bonds and other bonds filed and premiums on insurance’accruing during the
construction of the Work, and {c) any indemnity obligations of Subcontractor hereunder.

3.6 In the event changes or extras to this Contract are authorized pursuant to the General
Conditions annexed hereto, Subcontractor shall be entitled to no more than fifteen percent (15%) to cover
overhead, supervision, small tools and profit.

ARTICLE 4: * Scheduling

Concurrent with the execution of this Subcontract, the Subcontractor shall give the Construction
Manager a proposed detailed time and manpower schedule, providing for completion of the Work within the
time provided for on the Progress Schedule annexed hereto as Exhibit D, which, in the. Subcontractor's
reasonable opinion, is adequate and sufficient to allow completion of the Project by the date specified by
Construction Manager, taking info account the work of all other subcontractors necessary to complete the
Project. At the Construction Manager's reques!, Subcontractor shall revise the schedule approved by the
Construction Manager in accordance with the time and place requirements of the Project as reasonably
determined by Construction Manager in its sole and absolute discretion. The Construction Manager shall use
the above referenced schedule in preparing an integrated Progress Schedule for the Project lisiing the
sequence and dates for completion of the various segments of the Work. The Subcontractor shall complete the
Work in accordance with the Progress Schedule, including any revisions thereto provided by Construction
Manager. The Construction Manager exclusively shall control scheduling, including the periodic updating
thereof, if any, and the Subcontractor shall comply therewith. The Construction Manager shall have the right
to schedule other work at the same time and in the same areas as the Subcontractor's Work. The
Subcontractor shall coordinate its Work with any other subcontractors! werk in such manner as the
Construction Manager may direct te avoid conflict or interference with such work of others, shall participate in
the preparation of coordinated drawings of congested areas and shall conform the Work to the work of other
subcontractors to prevent discrepancies {and to avoid unnecessary cutting or patching) with contiguous work,
At its sole discretion, the Construction Manager may schedule Work during a time of, and from time fo time
during, winter conditions, The determination of when winter conditions exist shall rest exclusively with the
Construction Manager.

ARTICLE 5: Progress

5.1 The Subcontractor shall keep itself inforrned at all times of the progress of the Work, and of
the progress of others whose work may affect, or who may be affected by, its progress. At the Construction
Manager's request, the Subcontractor shall inform the Construction Manager about materials on hand,
progress made in the manufacturing and fabricating of materials for the Work, or any other matters relating to
the condition or progress of the Work, The Construction Manager, Owner's representatives and the Architect

REV,5,21.13 6 Initist Below: Plaza Construction Subcontractor

. Qn,at all times shall have free access to the office, shops and yards of the Subcontractor to verify any information
about the Work given by the Subcontractor, :

5.2 The Subcontractor, upon twenty-four {24} hours notice, in person or by duly authorized
representative having power to act and acceptable to Construction Manager, shall attend, at its own expense,
afl meetings or conferences that the Owner, Architect or Construction Manager may call, at the building site or
elsewhere, for the purpose of discussing progress of the Work, safety at the site, or ways to expedite the
completion of the Project.
ARTICLE 6: Timin

TIME 1S OF THE ESSENCE IN THE PERFORMANCE OF THIS CONTRACT. The Construction
Manager and/or the Owner may sustain financial loss if the whole Project or any part thereof is delayed
because the Subcontractor fails to perform any part of the Work in accordance with the Contract Documents,
or the milestone dates and Substantial and Final Completion dates set forth on the Progress Schedule annexed
hereto, as same may be modified from time to time, The Subcontractor shall begin the Work at the time
directed by the Construction Manager and shall perform its obligations under this Contract with diligence and
with sufficient manpower to maintain the progress of the Work as scheduled, without delaying other trades or
areas of work. At the request of the Construction Manager, the Subconiractor shall perform certain parts of
the Work before other paris, add exira manpower, or, order overtime labor in order to comply with the
Progress Schedule, all without any increase in the Contract Price (unless otherwise specifically provided in the
Scope of Work}.

ARTICLE 7; Bonds

At the request of the Construction Mena
labor and material payment bond within five
Such bonds shall be with a corporate surely
acceptable fo the Construction Manager, in th
Manager and the Owner as co-obligees.
Subcontractor shall faithfully, promptly and with
Contract on its part to be performed, {ii} pay all

ger, the Subcontractor shall furnish a performance bond and a
5) days after execution of this Coniract, at its own expense.
{licensed in the State in which the Project is located and}
6 amount of the Contract Price and shall name Construction
Such borids shall include provisions fo the effect that the
due diligence {i} perform all of the terms and provisions of this
of the Subcontracior's obligations to its employees, agents, all

subcontractors, materialmen, suppliers and others relating to the Work, and [iii] complete the various portions

of the Work in accordance with the terms of tl
form and substance mutvally satisfactory to the

he Contract Documents, and such bonds shall otherwise be in
Construction Manager and Owner. To the extent, if any, that

the Contract Price is increased in accordance with the Contract Documents, Subcontractor shall, upon request
of Construction Manager, cause the amount of such bonds fo be increased accordingly and shall promptly
deliver satisfactory evidence of such increase to Construction Manager. The Bonds shall further provide that
no change to or alteration of this Contract (including, without limitation, an increase in the Coniract Price, as
aforesaid}, extensions of time, change orders, premature payment or overpayment to the Subcontractor, will
release the surety, The Construction Manager may in its sole discretion utilize a default insurance program in
lieu of requiring Performance and Payment Bonds. In such a case, the Subcontractor acknowledges and
agrees that the Construction Manager may assign any or all of its rights under this Agreement to the default
insurance carrier.

ARTICLE 8: Subcontracts and Purchase Orders

Within five {5} days of the award of this Contract, or such earlier time as the Construction Manager
may direct, the Subcontractor shall provide to the Construction Manager a complete list of all its subcontractors
and suppliers for all parts of the Work for Construction Manager's approval. The Subcontractor shall notify
the Construction Manager in writing of any proposed changes in its subcontractors or suppliers not less than
five {5} days prior to such change, which notice shail specify the reasons for such proposed change. Without
limiting, diminishing or otherwise affecting Subcontractor's obligations hereunder, any such change shall be
subject to the approval of Construction Manager, which approval shall not be unreasonably withheld or
delayed. Subcontractor shall ensure that all of its subcontractors, vendors and suppliers are bound by the
General Conditions and Progress Schedule annexed hereto.

REV.S.21.13 7 initial Below:___ Plaza ction Subcontrastor

Qn,ARTICLE 9; Certain Warranties and Guarantees

91 Promptly upon completion of the Work, and as a condition precedent to final payment, the
Subcontractor shall assign and deliver to the Owner {through the Construction Manager] all guarantees from
third parties for materials, equipment and labor incorporated, into or used in connection with the Work,

9.2 The Subcontractor warrants that alf materials and equipment furnished under this Contract
will be new, ‘unless otherwise specified, and that all Work will be of good quality, free from improper
workmanship and defective materials and in conformance with the Contract Documents.

9.3 Without limitation of the foregoing or any other obligation of Subcontractor provided for in
the Contract Documents, immediately upon the Construction Manager's demand, the Subcontractor, at its own
expense, shall repair, replace, restore or rebuild, at the Construction Manager's option, any Work in which
defects in materials or workmanship may appear, or which is otherwise not in conformance with the other
warranties of Subcontractor hereunder.

94 The existence of the foregoing warranties and undertakings by Subcontractor shall not
relieve the Subcontractor of, or reduce the Subcontractor's liability for, latent defects and shall be in addition to
all of the Construction Manager's and Owner's other rights and remedies hereunder, under any olher Contract

_ Document or under law, and to any other guaranties or warranties, whether express or implied.

ARTICLE 10; Insurance

10.1 The Subcontractor, at its own expense, shall obtain and submit to the Construction
Manager, before undertaking any part of the Work, policies and certificates with receipts for the payment of
premiums from the Subcontractor's insurance carriers indicating coverage from companies, in amounts and on
such other terms as provided for hereinafter and in the “Insurance Schedule" attached fo this Agreement as
Exhibit E. Any “deductible” with respect to such coverage shall be submitted to, and approved in writing by,
Construction Manager, provided that any costs or damages not covered due to the approved deductible shall
be borne solely by Subcontractor. All such insurance shall be maintained by Subcontractor, af its expense,
until the Work has been compleied and all obligations of Subcontractor under the Contract Documents have
been satisfied! Any policy of insurance covering the Subcontractor's tools, equipment or facilities against loss
of physical damage, shall provide for a complete waiver of subrogation against the Construction Manager,
the Owner, and their respective members, officers, directors, employees, agents and servants,

0.2 All policies required of Subcontractor hereunder shall provide for notice to the Construction
Manager thirty (30) days before any change in or cancellation of such insurance, and shall otherwise be
acceptable fo the Construction Manager. Upon request, the Subcontractor shall furnish the Construction
Manager with evidence of insurance satisfactory to the Construction Manager for each subcontractor
employed by it. The insurance required herein shall in any event include blanket {broad form) contractual
liability insurance. The existence of insurance shall not be construed to limit the Subcontracior's liability under
this Contract.

0.3 The Subcontractor hereby waives all rights which arise by subrogation or otherwise that it

may have against the Owner or Construction Manager for damages caused by fie or other perils covered by
insurance referred to in this Article 10 or in the Insurance Schedule.

ARTICLE 11: Default and Termination

14 Any one or more of the following shall constitute an event of default by the Subcontractor:

A. The Subcontractor shall fail or refuse to perform the Work or comply with any term, condition or
provision of this Contract or of any of the other Contract Documents,

REV.5.21.13 & Initial Below:___Plaza Construction ‘Subcontractor

Orn,The Subconiractor shall fail or refuse to pay any of its subcontractors, suppliers or workers for any
materials, labor or other things incorporated info, or used in connection with the Work when such
payments are due; provided, however, that if the Subcontractor disputes the amount due to a worker,
subcontractor or supplier, and the Subcontractor, within wo (2] days of the due date of such payment,
at its own expense, posts a bond for the dispuled payment in amount and form satisfactory to the
Construction Manager as security for such payments, then such non-payment shall not constitute an

event of default hereunder.

The Subcontractor shall abandon the Work or reduce its labor force to a number insufficient, in the
Construction Manager's opinion, to complete the Work within the scheduled time.

Without limitation of the foregoing, any of the events described in the General Conditions as an event
of default shall occur.

11.2 [f any event of default described in Section 11.1 above occurs, then the Construction

Manager, af ifs option, at any time may:

A

Order the Subcontractor immediately to comply with any term, condition or provision of this Contract
or such other Contract Document;

Order the Subcontractor, within a specified time, to remove any defective work or materials and to
replace such work or materials with satisfactory work or materials;

Accept any defective work or materials and reduce the Contract Price accordingly;
Perform or arrange to have performed any of Subcontractor's duties or obligations hereunder;

Make any payments to satisfy the Subcontractor's obligations relating fo the Work for fabor,
materials, equipment, or insurance or other items;

Refuse to make any payments fo the Subcontractor for Work performed until the event of defoult is
cured to the satisfaction of Construction Manager; and/or

Upon three (3) days’ written notice to the Subcontractor, terminate in whole or in part this Contract on
behalf of Gwner and take possession of all materials, tools, equipment and appliances of the
Subcontractor and cause all the Work to be finished by whatever means, method or agency which the
Construction Manager, in its sole discretion, may choose and take any other steps the Construction
Manager, in its sole discretion, may choose to secure any labor, materials, equipment and services
and, in any event, the Owner shall have a tien on and may take over all Subcontractor's equipment,
tools, appliances and materials (whether on or offsite) and complete the Work; provided, however,
that if the default involves any breach of safety laws, regulations or requirements, only one (1) day's
written notice shail be required.

If the Construction Manager terminates this Contract on behalf of Owner, as aforesaid, the
Construction Manager (to the extent provided herein] and the Owner shall have no obligation to pay
for any Work performed after such termination, and will have no obligation to make ony further
payments fo the Subcontractor for Work performed before such termination until the Project has been
completed, accepted by the Owner, the Construction Manager has received full payment for the
Project from the Owner, and the Construction Manager determines to its complete satisfaction that
potential expenses, charges and claims relating to the performance of the Work have been satisfied
or satisfactorily bonded over. Such payments to the Subcontractor shall in any event be reduced by all
amounis due the Owner or the Construction Manager under the terms of this Contract,

11.3 The Construction Manager's choice of any remedy shall not operate to waive ony other

rights or remedies of Construction Manciger or Owner provided hereunder, or by law, against the

REV.S.21,13 9 Initial Below:__Plaza ffnstruction Subcontractor

nmSubcontractor or its surety. The Construction Manager, at his option, may choose more than one remedy or
choose one or more particular remedies at different times.

11.4 In the event of a Subcontractor default, the Subcontractor shall pay, immediately upon
demand therefor, all costs, losses, damages and expenses, including, without limitation, all administrative,
management, overhead and other direct or indirect expenses, including reasonable attorneys’ fees
(collectively, the "Costs") incurred by the Construction Manager or Owner in connection with and as a result of
any default by Subcontractor or-the exercise of any right or remedy upon Subcontractor's default, If the
Subcontractor does not pay the Costs immediately, the Construction Manager may withhold and deduct all
Costs from any payments of the Contract Price. If payments due to the. Subcontractor for completed portions of
the Work are not sufficient to cover the Costs, the Subcontractor immediately shall pay to Construction
Manager the full amount of ‘any ‘such excess with interest thereon at the maximum interest rate permitted by
law, The liability of the Subcontractor hereunder shall extend to and include the full amount of Costs incurred
and obligations assumed by the Construction Manager or Owner in good faith under the reasonable belief
that such Costs or obligations were necessary or required, whether actually necessary or required or not, (i} in
protecting and completing the Work and providing labor, materials, equipment, supplies and other items in
connection therewith or in recontracting the Work, and [ii} in settlement, discharge or compromise of any
claims, demands, suits and judgments pertaining to or arising oul of Work. An itemized statement of such
obligations and payments shall be prima facie evidence of the Subcontractor's liability.

11.5 This Agreement may be terminated by ihe Construction Manager without cause upon ten
{10} days prior written notice. In the event of such termination, Subcontractor shall be reimbursed such amount
as shall be due the Subcontractor for (1 that portion of the Wark satisfactorily performed prior to the effective
date of termination, and {2) reasonable costs directly incurred (but specifically excluding lost overhead, profits
and consequential damages or other lost opportunity costs} as a direct result of such termination.

ARTICLE 12: No Waiver Except in Writing

No action or failure to act by the Construction Manager shall constitute a waiver of any default in that
or any other instance, except fo the extent the Construction Manager specifically states in writing.

ARTICLE 13: Assignments

13.1: The Subcontractor shall not assign this Contract, in whole or in part, or hypothecate,
pledge or assign any payments due it under this Contract, without the Construction Manager's prior written
approval. Any such attempted unauthorized assignment shall be null and void. In any event, no subcontract
or approved assignment shall relieve or release in any way the Subcontractor from its obligations hereunder or
under the other Contract Documents.

13.2 This Agreement may, upon written notice, be assigned fo another entity designated by the
Construction Manager without the need for any action by the Construction Manager or approval by
Subcontractor and in such event the Subcontractor agrees to and shall continue to be bound by this
Agreement, and, in the event of such an assignment, Subcontractor shall continue to look solely fo the Owner
for payment and performance hereunder.

ARTICLE 14: Merger

All previous date orders, proposals, letters, oral or written promises and understandings relating to the
subject matter of this Contract, are hereby declared to be null and void, This Contract is complete and shal!
nol be interpreted by any reference to any previous letter, proposal, document or understanding, written or
oral, or other document or agreement, except as specifically provided in this Contract.

ARTICLE 15; Amendments

No amendments to this Contract shall change or modify this Contract unless in wrifing and signed by
both the Construction Manager and the Subcontractor.

REV.S.21.13 : 10 Initial Below: __ Plaza C tion Suboontractor

: QuARTICLE 16: Captions

The captions to the provisions of this Contract are for convenience only and are not ¢ part of this
Contract.

ARTICLE 17: Nofices,

Any notice required to be given by the terms and provisions of this Contract er by any law or
governmental regulation, either by the Construction Manager or Subcontractor (or which elther porly may
desire to give hereunder), shall be in writing and shall be personally delivered or forwarcled by overnight
express mail or registered or certified mail, retumn receipt requested, and shall be addressed fo the party hereto
fo whom directed, at its address, as herein stated fo the attention of MICHAEL J. GABBAY for Construction
Manager and CHUCK SPERRY for the Subcontractor. Either parly may change the address to which any notice
referred fo hersin is to be sent by giving written notice of such change of address to the other party in the
manner provided above, Notice personally delivered pursuant to this Article 17 shall be effective on the dats
of delivery. Notice given by mail shall be effective on the dote of receipt appearing on the return receipt, or,
in the absence of a return receipt, the date of attempted delivery.

ARTICLE 18: Miscellaneous

Each of the Exhibits attached hereto is hereby made a part hereof. if any provision of this Contract,
or the application thereof to any person or situation, fo any extent shall be held invalid or unenforceable, the
ramoinder of said Contract, and the application of such provision fo persons or situations other than those lo
which it shall have been held invalid or unenforceable, shall not be affected thereby, but shall continue valid
and enforceable to the fullest extent permitted by law. All provisions of this Agreement which, by their terms
require performance by either party hereto after termination of this Contract shail survive any such termination.

ARTICLE 19: ird Beneficia

Except as otherwise provided herein, no provision of this Contract shell in any way inure fo the benefit
of any third party {including the public at large} so as to constitute any such person a third party beneficiary of
this Contract or of any one or mote of the terms hereof or otherwise give rise to any cause of action in ony
person net a party hereto,

REVEAL nu Initial Below: __ Plazs Conftruetion ‘Subeontractor

C2oIN WITNESS WHEREOF, the parties hereto have executed this Contract as of the day and yeer first

above written,

CONSTRUCTION MANAGER:

SUBCONTRACTOR:

REV.S.21.13

PLAZA CONSTRUCTION CORP.

ie

Michael |. Gabbay, Executive Vice President
Print Name & Title

Baring Industries, Inc

a ___Nevade Corporation

— CLA bp.
" CHARLES & epelkny.

Print Name & Title PR EsIrp EVT

@/ 20/13

12 Initial Below:__Pfazs Coffstruction Subcontractor

CesIN WITNESS WHEREOF, the parties hereto have executed this Contract as of the day and year first
above written,

CONSTRUCTION MANAGER: PLAZA CONSTRUCTION CORP.

ju

Michael J, Gabbay, Exec ige P,
Print Name & Title
SUBCONTRACTOR: ~~~ Baring industries, Inc.
a ___Nevade Corporation
» CAbk

Print Wome E Tile DR ESTDENT-

6/0/13

REV.S.2013 2 Initial Below:___ Plaza Copstenctioa. Subsonteactor

C20IN WITNESS WHEREOF, the parties hereto have executed this Contract as of the day and year first

above written.

CONSTRUCTION MANAGER:

SUBCONTRACTOR;

REV.S.2L13

PLAZA CONSTRUCTION CORP,

By:
i nt
Print Name & Title
Baring Industries, inc.
a Nevads Corporation
By:
CHpaues &. speSe
Print Name & Tile PRESIDEN T
b/20f/3
a Initiat Below;__Plaza Conffruction Subcontractor

Cowr™o 7 7" D3D OO

REV5.21,13

LIST OF EXHIBITS TO TRADE SUBCONTRACT
AND GENERAL CONDITIONS

General Conditions

Plans and Specifications

Scope of Work

Progress Schedule

insurance Schedule

Performance and Payment Bonds
Wage Rates / Unit Prices
Alternate Prices

Project Site Safety Program

1B Tnitial Below:

Plaza

teuction

Subcontractor

ORCONSTRUCTION

EXHIBIT “A”

GENERAL CONDITIONS

Initial Below: Plaza oat SubcontractorARTICLE 1.
ARTICLE 2.
ARTICLE 3.
ARTICLE 4,
ARTICLE 5.
ARTICLE 6,
ARTICLE 7.
ARTICLE 8,
ARTICLE 9.
ARTICLE 10,
ARTICLE 11.
ARTICLE 12,
ARTICLE 13.
ARTICLE 14.
ARTICLE 15.
ARTICLE 16.
ARTICLE 17.
ARTICLE 18.
ARTICLE 19,
ARTICLE 20.

ARTICLE 21.

“PAGE
The Work .cccccssscceccseessnensnneereastecseasresecengeensens eistenecricieisnenerisrsseesasanesgeses 3
Subcontractors Contract Documents ..ccscsececsisseteenesessensenserenarenensersensesrenererene 3

The Architect

Hazardous Material .....csscsceseccseerssesnvsncsssussecscsssessessousareasenserrsesaversesseesee: O

Subcontractor's Responsibilities
Legal Obligations......csessecsssseseseessresssevecsseseessnenssericsteassesseererneenetonisontecoreessess 8

Testing & Inspection... .csisceessseess ces rseecssessrepresneneectorenneensiensasanereiceiseseerenraeees 10

Guarantees
Indemnification and Insurance... cesccescesccseerscsseeeeeesesssserpeneeceseneaseeneneseseanerseseeeney iW

Administration and Supervision of the Work ..c.scsessessessssesseeeriseenecescicreenrecnesnnees 12

Shop Drawings and Samples...

Construction Practices at the Site .sccccssssseecssecssseesserssssecseceneenmiesseesisssnessecaresses 15

Correction of Work
Acceptance of the Work ..ccccesesessscenssrrsrsseeveeessssnisnssesetennsarereneerreniseesrinseregs 17

PayMents oo. cccccsceseessseeesesseesseerenetscetsneesnrssersensensenenseersners ti fereseraesscstanteasertenen 19

Change Orders and Claims for Exira Cost or Time Extensions ...

Fast Track/Time Extension Delays ...cccecssesssesessssrssscnsnsscsssesesecmsieneensenersenennes 23
TOXOS ss cecsessssesesctscesssessenvoeceanecsuscsovevecsscersseepessecersustsanesssenanesseeserresserenereesen? 26
Cooperation With Lender ...cscescssssssesecssrsecsesssesecsessetieenseerecesseissneersaeseians 26
COPHONS cs cscsecceseseeseeseseeneseseessseeteneeressersneneetsicteeenseneicinntesansisssetessesaennnees 27
Confidentiality or Proprietary Information, .......

GEN.COND C.M.. Revised 5.21.13 . 2 Initicl Below: Plaza Construction Subcontractor

ernARTICLE 1: The Work

A.

The term "Work" includes the furnishing of labor or material undertaken by the Subcontractor pursuant
to the Contract Documents; Work includes, unless specifically excepted, the furnishing of all material,
labor, equipment, supplies, plant tools, scaffolding, transportation, superintendence, temporary
construction of every nature, contributions to union funds and benefits, insurance, taxes and all other
services and facilities necessary for the full performance and completion of the requirements of the
Coniract Documents, Work also means that which is produced, constructed or built pursuant to or
reasonably inferable from the Contract Documents, The Work shall include the obligation of any
Subcontractor who bids to perform any portion of the Work to visit the site of the proposed Work, fully
acquaint and familiarize himself with the conditions as they exist and the character of the operations to
be carried on under the proposed Contract, and make such investigation as he may see fit so that he
shall fully understond the facilities, physical conditions and restrictions attending the Work under the
Contract. Each such Subcontractor shall also thoroughly examine and become familiar with the
drawings, specifications and associated bid documents and by execution of this Contract accepts them
as sufficiently complete to properly perform the specified Work at the Contract Price.

ARTICLE 2: Subcontractor's Contract Documents

A

The Contract Documents are complementary and are intended to include or imply all items required for
the proper execution and completion of the Work, Any item of Work mentioned in the specifications
and not shown on the drawings, or shown on the drawings and not mentioned in the specifications,
shall be provided by the Subcontractor as if shown or mentioned in both.

The drawings and specifications are "scope" documents which indicate the general scope of the
Project in terms of the architectural design concept, the dimensions of the buildings} or other
improvements, the type of structural, mechanical, electrical and utility systems and an outline of major
architectural elements of consiruciion. As "scope documents the drawings and specifications do not
necessarily indicate or describe all Work required for the full performance and completion of the
Work. Contracts and agreements for material will be let on the basis of such documents with the
understanding that the Subcontractors and materialmen are to furnish all items required for proper
completion of the Work without edjustment to Contract Price, It is intended that the Work be of sound
and quality construction and the Subcontractors shall be responsible for the inclusion of adequate
amounts to cover installation of items indicted, described or implied in the portion of the Work fo be
performed by. them. Subsequent drawings and specifications may be issued for purposes of
construction, which will more completely detail all requirements of the Work.

Generally, the specifications describe Work which cannot be readily indicated on the drawings and
indicate types, qualities and methods of installation of the various materials and equipment required
for the Work. It is not intended to mention every item of Work in the specifications which can be
adequately shown on the drawings nor to show on the drawings all items of Work described or
required by the specifications even If they are such nature that they could have been shown thereon.
All materials or labor for Work, which is shown on the drawings or is reasonably inferable therefrom
as being necessary to produce a finished job shall be provided by the respective Subcontractors
whether or not the Work is expressly covered in the specifications.

In the event there is a discrepancy between the various Contract Documents, the document imposing
the greater duty or greater quantity shall control. If the difference is between the requirements of the
drawings or specifications or differences within the drawings or the specifications themselves, then

GEN.COND C.M.. Revised 5.21.13 3 Initic! Below: Plaza Constgction __ Subcontractor

Q2p,they shall be submitted to the Construction Manager who shall bring the same to the attention of
Architect who, in Consultation with Owner, shall decide which of the conflicting requirements shall
govern and the Subcontractor doing such Work shall perform the Work in accordance with such
decision and without any change in his Contract Price. Any Work performed by Subcontractor
relating to any such differences prior to resolution as herein provided shall be performed al
Subcontractor’s sole risk, cost and expense. All the Contraci Documenis shall be read together as
complementary and rights and obligations thereunder shall be deemed cumulative.

Included in the Scope of Work and this Contract is the complete coordination of this Work with the
Work of other trades and the complete integration of the various systems furnished and installed as
part of this Contract with the systems provided by others. As part of the coordination procedure this
Subcontractor shall attend meetings as required by the Architect and Construction Manager and
provide information for review by other trade contractors, 4s well as review information provided by
athers which coordination shall be done in such a manner as to be expeditious and in no way causing
delay to other trades or the Project in general. Coordination and integration of systems and/or
equipment will also include the development of composite drawings, and includes but is not limited to,
the foliowing:

(a) Location and/or relocation of equipment with the confines of a given space or
general area prior to installation to maximize accessibility, serviceability and improve
operation as well as resolve conflicts between trades.

fb} Provide adequate qualified personnel to install check out and/or verify operation of
equipment and/or sysiems, which require the involvement of the Subcontractor as
defined in the Contract Documents, This includes testing by representatives of the
Engineers, Architects or Owner's Agents. .

fc} Provide all necessary preparatory Work to permit atiachment, connection and/or
integration of any kind for and/or with the Werk of other trades. No additional costs
will be accepted for any relocations or equipment or appurtenances due to conflicts
with existing or new systems. ‘

tt is understood and agreed that refinement and detailing will be accomplished from time fo time with
respect to the plans and specifications, No adjustment shall be made to the Contract Price or time for
completion of the Work unless such refinement or detailing results in changes in the scope of quality,
function and/or intent of the plans and specifications not reasonably inferable or anticipatable by a
trade contractor of Subcontractor's expertise and experience,

ARTICLE 3: ‘The Architect

A

The Architect shall be one of the Owner's representatives during the construction period and he shall
review the Work in progress on behalf.of the Owner. The Architect will not be responsible for
construction means, methods, techniques, sequences or procedures or for safely precautions and
programs in connection with the Work and he will not be responsible for any Subcontractor's failure to
carry out the Work in accordance with the Contract Documents.

The Architect shall be the interpreter of the drawings and specifications. in the event of dispute, the
Architect shall side with none of Owner, the Construction Manciger or the Subcontractors, and the
Architect shall also