Your recipients will receive an email with this envelope shortly and will be able to access it on trellis. You can always see your envelopes by clicking the Inbox on the top right hand corner.
Your subscription has successfully been upgraded.
§ 9A:19-1.7. Authorization process
(a) The Secretary shall establish a review committee comprised of representation that may include the Office of the Secretary of Higher Education, the New Jersey Educational Facilities Authority, the New Jersey Department of Labor and Workforce Development, the New Jersey Department of Education, and any other State entity with technical expertise to evaluate project grant applications and make recommendations on funding.
(b) The Secretary shall examine the recommendations of the review committee and shall approve or disapprove a grant in accordance with N.J.A.C. 9A:19-1.6 and establish the amount of the grant in accordance with this subchapter.
(c) The total dollar amount of a grant approved for any county college shall not exceed $ 4,000,000.
(d) The Secretary shall prepare and deliver a list of projects that meet the eligibility requirements set forth by the Securing Our Children's Future Fund and by this chapter that have been approved for funding by the Secretary, including the amount of each project grant, to presiding officers of each house of the Legislature on a date that both houses are in session. The list shall be deemed to be approved in its entirety, unless the Legislature adopts a concurrent resolution stating that the Legislature is not in agreement with the list within 60 days following the date of transmittal of the list to the Legislature. The payment of project grants on the list of projects shall be subject to the prior appropriation of sufficient funds pursuant to section 14 of the Act for total project amounts so listed.
(e) Upon authorization of a grant pursuant to (d) above, funding of the grant shall be contingent upon:
1. Appropriation of sufficient funds pursuant to P.L. 2018, c. 119, §14 for the project set forth in the list of eligible projects sent to the Legislature;
2. Execution of a grant agreement with the Secretary; and
3. The county college's continued compliance with the grant agreement.
(f) Each recipient of a grant shall provide such information as the Secretary may request during the use of the grant and the process of the project.
(g) The Secretary may, consistent with the Act, allocate any balance of an approved grant to another approved grant, contingent on the following:
1. If a county college determines not to undertake a project for which a grant was awarded;
2. To adjust for actual project expenses in a manner consistent with the approved project;
3. If the project is not substantially completed, and the grant substantially disbursed, six months after the estimated construction completion date set forth in the grant application, as adjusted for any actual delay to the county college entering into a construction contract pursuant to (e) above; or
4. If a county college fails to comply with the provisions of the grant agreement as set forth in (e) above.
(h) No reallocation shall be made pursuant to (g) above if:
1. Delays are the result of Federal, State, or local government approvals or regulatory requirements not attributable to the county college; or
2. In the sole determination of the Secretary, there are other compelling and documentable reasons.
(i) Failure to comply with the grant agreement may result in the applicant's obligation to repay the grant funds.
(Adopted by 52 N.J.R. 794(a), effective April 6, 2020)
ESX-L-003542-24 05/23/2024 4:37:25 PM Pglof29 Trans ID: LCV20241320822 GREGORY R. MILNE, ESQ. — 023641989 FOSS, SAN FILIPPO & MILNE, LLC 225 Broad Street P.O. Box 896 Red Bank, New Jersey 07701-0896 (732) 741-2525 (732) 741-2192 (fax) O…
May 23, 2024
Active
ESX-L-003213-22 06/02/2022 10:16:43 AM Pglof8 Trans ID: LCV20222097242 GREGORY R. MILNE, ESQ. — 023641989 FOSS, SAN FILIPPO & MILNE, LLC 225 Broad Street P.O. Box 896 Red Bank, New Jersey 07701-0896 (732) 741-2525 (732) 741-2192 (fax) Our File Number: 8494.19851 grmilne@fsfm-law.com Attorneys for Plaintiff, FRESHSTART VENTURE CAPITAL CORP. FRESHS…
ESX-L-003213-22 06/02/2022 10:16:43 AM Pglof8 Trans ID: LCV20222097242 GREGORY R. MILNE, ESQ. — 023641989 FOSS, SAN FILIPPO & MILNE, LLC 225 Broad Street P.O. Box 896 Red Bank, New Jersey 07701-0896 (732) 741-2525 (732) 741-2192 (fax) Our File Number: 8494.19851 grmilne@fsfm-law.com Attorneys for Plaintiff, FRESHSTART VENTURE CAPITAL CORP. FRESHS…
BER-L-000060-19 11/09/2020 8:23:44 PM Pg 1 of 3 Trans ID: LCV20202021985 LYNCH LYNCH HELD ROSENBERG, P.C. JOSEPH M. CERRA, ESQ. NJ ATTORNEY ID# 050991988 440 State Route 17 North Hasbrouck Heights, NJ 07604 (201) 288-2022 Attorneys for Plaintiff, FRIDA MILMAN : SUPERIOR COURT OF NEW JERSEY FRIDA MILMAN, : LAW DIVISION: BERGEN COUNTY : …
Jan 03, 2019
Closed
MON-DC-003815-20 09/03/2020 11:28:04 AM Pg 1 of 2 Trans ID: SCP20201536471 Marc A. Leckstein, Esquire Attorney Id # 000421999 Leckstein & Leckstein, LLC 463 Prospect Avenue Post Office Box 231 Little Silver, New Jersey 07739 (o) (732) 530-6500 / (f) (732) 530-3606 e-mail: marc@lecksteinlaw.com Attorneys For Plaintiff : SUPERIOR COURT OF NEW JERSEY LAW DIVISION - SPECIAL CIVIL PART…
Jun 10, 2020
Defaulted
Monmouth County, NJ
Sep 03, 2020
For full print and download access, please subscribe at https://www.trellis.law/.
Please wait a moment while we load this page.